Loading...
2012 Paving Construction Engineering Services_201204271528283357ENGINEERING SERVICES AGREEMENT VILLAGE OF OAK BROOK 2012 PAVING CONSTRUCTION ENGINEERING SERVICES THIS AGREEMENT, made and entered into this 10th day of April, 2012, by and between Christopher B. Burke Engineering, Ltd., (hereinafter referred to as "ENGINEER") and the Village of Oak Brook, a municipal corporation (hereinafter referred to as "VILLAGE") covers certain professional engineering services in connection with the 2012 Paving Construction Engineering Services, (hereinafter referred to as "PROJECT"). The VILLAGE wishes to retain ENGINEER for these certain professional engineering services and ENGINEER is willing to perform such services for the compensation and in accordance with the terms and conditions described in this Agreement. NOW, THEREFORE, in consideration of the mutual benefits, covenants and agreements contained within this Agreement, the parties agree as follows: SCOPE OF SERVICES ENGINEER agrees to perform engineering consulting services as defined in the Scope of Services attached as Appendix I and made a part of this Agreement. 2. COMPENSATION AND PAYMENT ENGINEER shall be paid by VILLAGE for all services stipulated within this Agreement according to the Compensation Schedule attached as Appendix II and made a part of this Agreement. Payment to ENGINEER shall be made by VILLAGE upon receipt of ENGINEER'S monthly invoice. The invoice shall consist of a summary of direct labor hours by ENGINEER'S standard job classification times the respective factors as depicted in Appendix II plus listing of reimbursable costs incurred with copies of appropriate invoices. The invoice will state the phase of work for which it applies, if a multi -phase scope is used (e.g., design, construction, etc.). If VILLAGE identifies an item in the invoice which appears to be in error, VILLAGE may withhold the amount in question, pay the balance of the invoiced amount, and provide ENGINEER with a statement concerning the questioned item. Alternatively, VILLAGE may pay the invoiced amount in full, provide ENGINEER with a statement of the questioned item, and an adjustment, if appropriate, will be made in the next subsequent invoice submitted by ENGINEER. Engineer will mark "Invoice and final" on the invoice which closes out this contract or a phase of the contract. If VILLAGE fails to make any payment due ENGINEER for services and expenses, including amounts wrongly withheld, within thirty (30) days after submittal of ENGINEER'S billing thereof, the amounts due ENGINEER shall include a charge at the rate of one percent (I.0) per month from such thirtieth (30th) day; and, in addition, the ENGINEER may, after giving Page 1 2012 paving engineering.doe seven (7) days written notice to VILLAGE, suspend services under this Agreement until it has been paid in full the amounts due it for services and expenses. During the period of any such suspension, the parties shall have the same rights and obligations as are provided by Subsection 5(e) of this Agreement. 3. TIME SCHEDULE The services required by this Agreement shall be completed in accordance with the Time Schedule attached as Appendix III and made a part of this Agreement. It is recognized by the parties that the Time Schedule may be contingent upon factors beyond the control of either party. Both parties will take all reasonable steps to adhere to the Time Schedule. 4. TERM OF AGREEMENT Unless extended by amendment, this Agreement shall terminate at the time of receipt of final payment by the ENGINEER, provided that all warranties and representations shall survive said final payment. 5. GENERAL TERMS AND CONDITIONS a. Modification The nature and the scope of services specified in this Agreement may only be modified by written amendment to this Agreement approved by both parties. b. Relationship between ENGINEER and VILLAGE ENGINEER shall serve as VILLAGE'S professional engineering consultant in those phases of the PROJECT to which this Agreement applies. The relationship is that of a buyer and seller of professional services, and it is understood that the parties have not entered into any joint venture or partnership with the other. C. Responsibility of the ENGINEER That all plans and other documents furnished by the ENGINEER pursuant to this Agreement will be endorsed by him and will show his professional seal where such is required by law. Notwithstanding anything to the contrary which may be contained in this Agreement or any other material incorporated herein by reference, or in any agreement between VILLAGE and any other party concerning the PROJECT, ENGINEER shall not have control or be in charge of and shall not be responsible for the means, methods, techniques, sequences or procedures of construction, or the safety, safety precautions or programs of VILLAGE, the construction contractor, other contractors or subcontractors performing any of the work or providing any of the services on the PROJECT, nor shall ENGINEER be responsible for the acts or omissions of VILLAGE provided that the ENGINEER has properly executed his duties. ENGINEER shall not be responsible for the failure of VILLAGE, any architect, engineer, consultant, contractor or subcontractor to carry out their respective responsibilities in accordance with the PROJECT documents, or any other agreement concerning the PROJECT. Any provision which purports to amend this provision shall be without effect unless it contains a reference that the content of this Subsection 5(c) is expressly amended for the purposes described in such amendment and is signed by ENGINEER. Page 2 2012 paving engineering.doo d. Corrections In the event plans, surveys or construction staking is found to be in error and revisions of the plans or survey or construction staking are necessary, the ENGINEER agrees that he will perform such work without expense to the VILLAGE, even though final payment has been received by him. He shall give immediate attention to these changes so there will be a minimum delay to the contractor. e. Suspension of Services VILLAGE may, at any time, by written order to ENGINEER (Suspension of Services Order), require ENGINEER to stop all, or any part of, the services required by this Agreement. Upon receipt of such an order, ENGINEER shall immediately comply with its terms and take all reasonable steps to minimize the occurrence of costs allocable to the services covered by the order. VILLAGE, however, shall pay all costs associated with suspension, including all costs necessary to maintain continuity and the staff required to resume the services upon expiration of the suspension of services order. ENGINEER will not be obligated to provide the same personnel employed prior to suspension when the services are resumed, in the event the period of any suspension exceeds thirty (30) days. VILLAGE will reimburse ENGINEER for the costs, if any, of such suspension and re -mobilization. Termination 1) Either party to this Agreement shall have the right to terminate this Agreement with or without cause upon serving thirty (30) days written notice upon the other party. 2) Upon such termination, the liabilities of the parties to this Agreement shall cease, but they shall not be relieved of the duty to perform their obligations up to the date of termination. All warranties and the provisions of Section 5, Paragraph I shall be in full force and effect after termination. 3) Upon such termination, ENGINEER shall cause to be delivered to the VILLAGE all drawings, specifications, partial and completed estimates, and any and all other data concerning the PROJECT which ENGINEER is then accomplishing for the VILLAGE. ENGINEER shall be paid for any services completed and any services partially completed in accordance with Sections 2 and 3. g. Warranties In addition to the covenants herein made, the ENGINEER warrants: 1) That he will render engineering services in accordance with generally accepted and currently recognized engineering practices and principles. h. Representations In addition to the covenants herein made, the ENGINEER represents and agrees: Page 3 2012 paving engineering.doe 1) That all plans and special provisions to be furnished by the ENGINEER pursuant to this Agreement will be in accordance with the current standard specifications and policies of the VILLAGE, it being understood that all such plans and drafts shall, before being finally accepted, be subject to approval by the VILLAGE. 2) That he has not employed or retained any company or person, other than a bona fide employee working solely for the ENGINEER, to solicit or secure this Agreement, and that he has not paid or agreed to pay any company or person, other than a bona fide employee working solely for the ENGINEER, any fee, commission, percentage, brokerage fee, gifts, or any other consideration, contingent upon or resulting from the award or making of the Agreement. For breach or violation of this warranty, the VILLAGE shall have the right to annul this Agreement without liability, or in its discretion to deduct from the Agreement price or consideration, or otherwise recover, the full amount of such fee, commission, percentage, brokerage fee, gift, or contingent fee. 3) That he is qualified technically and is conversant with the policies applicable to the PROJECT; and that he has and will furnish sufficient, properly trained and experienced personnel to perform the services enumerated herein. 4) That he will not employ, for the duration of this Agreement, any person presently employed by the VILLAGE without the written consent of the VILLAGE. Documents Property of VILLAGE Drawings, specifications, reports, and any other documents prepared by ENGINEER in connection with any or all of the services furnished hereunder shall be the property of VILLAGE. ENGINEER shall have the right to retain copies of all documents and drawings for its files. All construction drawings shall be prepared on 24" x 36" mylar sheets. If construction services are a part of the ENGINEER's work, he will revise the original mylar drawings to show "As -Built" conditions and will deliver them to the VILLAGE within thirty (30) days after completion of construction and before final payment to the ENGINEER. ENGINEER will stamp these drawings "Record Drawings". If construction services are not part of the ENGINEER's work, he will deliver the original mylar drawings to the VILLAGE upon request and before final payment to the ENGINEER. Access to Records The ENGINEER shall maintain all books, documents, papers, accounting records and other evidence pertaining to his costs incurred by reason of this Agreement and agrees to make such material available, at his office at the address indicated in Section 5, Paragraph u of this Agreement, at all reasonable times during the life of this Agreement and for a period of three (3) years from the date of final payment of the obligations of this Agreement by the VILLAGE or such longer time as requested by the VILLAGE, for inspection by personnel of the VILLAGE, or any authorized representative of the VILLAGE, and copies thereof shall be furnished if requested. The cost of any copies shall be paid by the VILLAGE. Page 4 2012 paving engineering.doc k. Reuse of Documents All documents, including drawings and specifications furnished by ENGINEER pursuant to this Agreement, are intended for use on the PROJECT only. They should not be used or modified by VILLAGE or others on extensions of the PROJECT or any other project without specific written verification or adaptation by ENGINEER. Any reuse or modification without written verification or adaptation by ENGINEER shall be at VILLAGE's sole risk, and VILLAGE shall indemnify and hold harmless ENGINEER from all claims, damages, loses, and expenses, including reasonable attorneys' fees, arising out of or resulting from such unauthorized reuse or modification. Indemnification ENGINEER agrees to indemnify, hold harmless, and defend (or pay the VILLAGE for the costs of defense) the VILLAGE and any of its officers, employees, or agents from and against all liability, claims, demands, and causes of action arising out of or related to any loss, damage, injury, death, or loss or damage to property resulting from any negligence, errors or omissions by the ENGINEER in the performance of this Agreement, unless such loss, damage, injury, or loss or damage to property results from or arises out of the negligent acts or omissions by the VILLAGE or its officers, employees or agents. VILLAGE agrees to indemnify, hold harmless, and defend (or pay the ENGINEER for the costs of defense) the ENGINEER and any of its officers, employees, or agents from and against all liability, claims, demands, and causes of action arising out of or related to any loss, damage, injury, death, or loss or damage to property resulting from any negligence, errors or omissions by the VILLAGE in the performance of this Agreement, unless such loss, damage, injury, or loss or damage to property results from or arises out of the negligent acts or omissions by the ENGINEER or its officers, employees or agents. In the event of joint or concurrent negligence of ENGINEER and VILLAGE, each shall bear that portion of the loss or expense that its share of the joint or concurrent negligence bears to the total negligence (including that of third parties) which caused the personal injury or property damage. M. Entire Agreement This Agreement sets forth all the covenants, conditions and promises between the parties. There are no covenants, promises, agreements, conditions or understandings between the parties, either oral or written, other than those contained in this Agreement. n. Governing Law This Agreement shall be governed by the laws of the State of Illinois both as to interpretation and performance. Page 5 2012 paving engineering.doc o. Successors and Assigns The terms of this Agreement shall be binding upon and inure to the benefit of the parties and their respective successors and assigns; provided, however, that neither party shall assign this Agreement in whole or in part without the proper written approval of the other. p. Waiver of Contract Breach The waiver of one party of any breach of this Agreement or the failure of one party to enforce at any time, or for any period of time, any of the provisions hereof, shall be limited to the particular instance, shall not operate or be deemed to waive any future breaches of this Agreement, and shall not be construed to be a waiver of any provision, except for the particular instance. q. Severability of Invalid Provisions If any provisions of this Agreement shall be held to contravene or be invalid under the laws of any particular State, County or jurisdiction where used, such contravention shall not invalidate the entire Agreement, but it shall be construed as if not containing the particular provision or provisions held to be invalid in the particular State, County or jurisdiction and the rights or obligations of the parties hereto shall be construed and enforced accordingly. r. Force Majeure Neither VILLAGE nor ENGINEER shall be liable for any fault or delay caused by any contingency beyond their control, including, but not limited to, acts of God, wars, strikes, walkouts, fires, or natural calamities. S. Access and Permits VILLAGE shall arrange for ENGINEER to enter upon public and private property and shall obtain all necessary approvals and permits required from all governmental authorities having jurisdiction over the PROJECT. VILLAGE shall pay costs (including ENGINEER's employee salaries, overhead, and fee) incident to any effort by ENGINEER toward assisting VILLAGE in such access, permits or approvals if ENGINEER performs such services as directed by.the VILLAGE. t. Designation of Authorized Representatives Each party shall designate one or more persons to act with authority in its behalf in respect to appropriate aspects of the PROJECT. The persons designated shall review and respond promptly to all communications received from the other party. Page s 2012 paving engineering.doc U. Address for Notices Whenever it is provided in this Agreement that notice shall be given or other communication sent to ENGINEER, such notices or communications shall be delivered or sent to: Christopher B. Burke Engineering, Ltd. 9575 West Higgins Road Suite 600 Rosemont, Illinois 60018 Attn: Orion Galey, PE Whenever it is provided in this Agreement that notice shall be given or other communication sent to the VILLAGE, such notices or communications shall be delivered or sent to: VILLAGE OF OAK BROOK 1200 Oak Brook Road Oak Brook, Illinois 60523 tiI Attn: Michael Hullihan Public Works Director Notices personally delivered or sent via U.S. Mail, postage prepaid, shall be deemed, for all purposes, proper notice. V. Insurance ENGINEER agrees to obtain and maintain, for the term of this Agreement, and for a period of twelve (12) months after the services contracted for hereunder have been completed, insurance hereinafter provided, furnishing a certificate or certificates of insurance to the VILLAGE prior to commencing work under this Agreement. The certificate or certificates of insurance shall be in a form satisfactory to the VILLAGE from companies authorized to do business in Illinois and shall provide that the policies referred to shall not be canceled or changed without first giving thirty (30) days written notice thereof to the VILLAGE. Said insurance requirements are attached as Appendix IV and made a part of this Agreement. The VILLAGE shall be named as an additional insured. W. Additional Services ENGINEER shall supply such additional services as requested in writing by VILLAGE and agreed to by ENGINEER in connection with the PROJECT. Separate proposals shall be submitted by ENGINEER for furnishing these additional services. Compensation for such additional services shall be negotiated by the parties and included in this Agreement by a written amendment. X. Incorporation of Rider No. 1 Rider No. 1 is attached to this agreement and made a part hereof as though fully set forth herein. Page 7 2012 paving engineering.doc IN WITNESS WHEREOF, the parties set their hands and seals on the date first written above. VILLAGE OF OAK BROOK Chr' I �, Ltd. BY. Duly Authorized Officer Page a 2012 paving engineering.doc ATTEST: "Secetary ... Nk. - SCOPE OF SERVICES Per proposal submitted by Christopher Burke Engineering, Ltd. dated April 4, 2012. Page 9 2012 paving engineering.doc APPENDIX II COMPENSATION SCHEDULE Per proposal submitted by Christopher Burke Engineering, Ltd. dated April 4, 2012. Page 10 2012 paving engineering.doc APPENDIX III TIME SCHEDULE Per proposal submitted by Christopher Burke Engineering, Ltd. dated April 4, 2012. Page 11 2012 paving engineering.doc APPENDIX IV Insurance Engineer shall maintain for the term of this Agreement, and for a period of twelve months after the services is contracted for hereunder have been completed, insurance policies covering: Workers Compensation and Employers Liability Insurance: Statutory limits = $500,000 per accident. Comprehensive General Liability Insurance: $1,000,000 per occurrence combined single limit. 3. Comprehensive Automobile Liability Insurance: $1,000,000 combined single limit, any auto. 4. Professional Liability Insurance (errors and omissions): $1,000,000 per claim and in aggregate. 5. Umbrella or excess liability: $1,000,000 per occurrence. If ENGINEER carries Comprehensive General Liability Insurance in an amount of $2,000,000 or greater, this requirement may be waived. 6. Engineer will provide the Village with a certificate of insurance and additional insured endorsement showing the Village added to the General Liability Insurance as an additional insured. Coverage shall not be suspended, voided, canceled, or reduced except after thirty (30) days prior written notice by certified mail has been given to the Village. If a standard Certificate of Insurance form is used with a cancellation clause, the words "endeavor to" and "but failure to mail such notice shall impose no obligation or liability of any kind upon the company, its agents or representatives" will be stricken or crossed out. Page 12 2012 paving engineering.doc RIDER NO, 1 TO AGREEMENT DATED APRIL 4, 2012 BETWEEN THE VILLAGE OF OAK BROOK, ILLINOIS AND CHRISTOPHER B. BURKE ENGINEERING, LTD. FOR THE 2012 PAVING CONSTRUCTION ENGINEERING SERVICES R-1. Conflicts. This Rider constitutes a part of the agreement ("Agreement") dated April 4, 2012 between the Village of Oak Brook, Illinois ("Village') and Christopher B. Burke Engineering, Ltd. ("Engineer") for the 2012 Paving Project ("Project"). In the event of any conflict between the terms and provisions of this Rider and those contained in the Agreement or any other contract document, the terms and provisions of this Rider shall prevail. R-2. Commencement. The date of commencement of Work by the Engineer shall be agreed upon by both the Village and Engineer. R-3. Statutory Provisions. The Engineer shall comply with the provisions of the Employment of Illinois Workers on Public Works Act, 30 ILCS 570/0.01, et seq.; the Drug Free Workplace Act, 30 ILCS 580/1, et seq.; the Human Rights Act, 775 ILCS 5/1-101, et seq.; and the Prevailing Wage Act, 820 ILCS 130/0.01, et seq.; the Veterans Preference Act, 330 ILCS 55/0.01 et seq.; but nothing herein shall require the application of those Acts unless required by state law. R-4. Bid Rigging. The Engineer hereby certifies that it is not barred from bidding on or entering into this Agreement as a result of a violation of Article 33E of the Criminal Code of 1961, 720 ILCS 5/1-1, et seq. R-5. Arbitration/Litigation/Venue. All disputes between the Village and the Engineer shall, at the election of either party, be the subject of a civil suit. Venue for any such suit shall lie in the Circuit Court of the 18`h Judicial Circuit (DuPage County). R-6. Termination. The Village reserves the right at any time and in its absolute discretion to terminate the services of the Engineer by giving written notice to the Engineer. In such event, the Engineer shall be entitled to, and the Village shall reimburse the Engineer for, an equitable portion of the Engineer's fee based on the portion of the services completed prior to the effective date of termination. R-7. Miscellaneous. The provisions which follow shall apply generally to the obligations of the parties under this Agreement: a. This Agreement may not be amended except pursuant to a written instrument signed by both parties. b. This Agreement is binding upon the successors and assigns of the Parties. C. The waiver by either party of any breach or violation of any provision of this agreement shall not be deemed to be a waiver or a continuing waiver of any subsequent breach or violation of the same or any other provision of this Agreement. d. Each of the parties to this Agreement represents and warrants that it has the full right, power, legal capacity, and authority to enter into and perform its Page 13 2012 paving engineering.doc respective obligations hereunder and that such obligations shall be binding upon such party without the requirement of the approval or consent of any other person or entity in connection herewith. e. This Agreement contains the entire understanding between the Parties with respect to the subject matter herein. There are no representations, agreements, or understandings (whether oral or written) between or among the parties relating to the subject matter of this Agreement which are not fully expressed herein. f. This Agreement creates no rights, title or interest in any person or entity whatsoever (whether under a third party beneficiary theory or otherwise) other than the Parties. g. This Agreement may be executed in counterparts. Facsimile signatures shall be sufficient. h. Under no circumstances shall this Agreement be construed as one of agency, partnership, joint venture, or employment between the Parties. The Parties shall each be solely responsible for the conduct of their respective officers, employees and agents in connection with the performance of their obligations under this Agreement. R-8 Burke Terms and Conditions not Applicable. The Village and Engineer acknowledge that the Engineer's proposal attached to this Agreement and setting forth the services, pricing, and time schedules that are incorporated in the Agreement as appendices I, II, and III ("Proposal"), also includes a copy of that certain document entitled "Christopher B. Burke Engineering, Ltd. General Terms and Conditions", consisting of 10 pages and 30 paragraphs dated June 13, 2005 (collectively, the "Burke Terms and Conditions"). The Village and the Engineer acknowledge and agree that the Burke Terms and Conditions: (1) do not and are not intended to bind the parties to this Agreement, (2) are not incorporated as terms or conditions of the Agreement, (3) are entirely superseded by the terms of the Agreement, and (4) are included in the attached Proposal for the sole purpose of accurately depicting the Proposal as submitted to the Village. The execution of this Agreement by the Village does not constitute, nor shall be interpreted as, an acceptance by the Village of the Burke Terms and Conditions or the incorporation of the Burke Terms and Conditions into this Agreement. In a Village President Page 14 2012 paving engineering.doe CHRISTOPHER B. BURKjE EN By: Its: Attest: By: Charlotte Pruss Village Clerk Page 15 2012 paving engineering.doe Attest: By: Its: CHRISTOPHER B. BURKE ENGINEERING, LTD. 9575 West Higgins Road Suite 600 Rosemont, Illinois 60018 TEL (847) 823-0500 FAX(847) 823.0520 April 4, 2012 Village of Oak Brook 1200 Oak Brook Road Oak Brook, IL 60523 Attention: Mr. Michael Hullihan, PE, Public Works Director Subject: Proposal for Professional Engineering Services 2012 Paving Project (CBBEL Project No. 110339) Dear Mr. Hullihan: Christopher B. Burke Engineering, Ltd. (CBBEL) is pleased to submit this proposal to perform construction engineering services for the Village's 2012 Paving Project. We understand that the Village will use Infrastructure Funds therefore; [DOT coordination will not be required. Included below you will find our Understanding of the Assignment, Scope of Services and Determination of Fee. UNDERSTANDING OF THE ASSIGNMENT CBBEL understands that the Village of Oak Brook would like to rehabilitate all of the streets located in the Saddle Brook subdivision, complete sidewalk and pavement striping Improvements at the Library and Fire Station #1 parking lots, complete full depth pavement patching along Kensington Court, complete full depth pavement patching through a portion of Brook Forest subdivision, reconstruct a portion of the Butler Government Center (Village Hall) parking lot, and extend the guard rail along the east side of York Road, north of the bridge over 1-88. The improvements of these project areas are described as the 2012 Paving Project. The project areas and proposed improvements are further described as follows: Area 1 (Saddle Brook Area 1): This area includes the resurfacing of Ridgewood Court, Saddle Brook Drive, Carriage Court, Blue Grass Court, Hambletonian Drive, Forest Mews Drive, Derby Court, Steeple Ridge Court; Bridle Path Court, Suffolk Lane, approximately 17,280 lineal feet (3.30 miles). The proposed improvements will include drainage structure repairs, partial curb and gutter repair, hot -mix asphalt surface removal of 4" depth at curb line tapered to 2" at center line, approximately 10% full -depth patching (7"), GlasGrid crack control, 2-1/4" binder course and 2" surface course. Area 2 (Saddle Brook Area 2): This area includes the resurfacing of Brougham Lane, Red Stable Way, and Red Stable Court approximately 2,950 lineal feet (0.56 miles). The proposed improvements will include drainage structure repairs, partial curb and gutter repair, hot -mix asphalt surface removal 3" at curb line tapered to 1" at center line, approximately 5% full -depth patching (8"), GlasGrid crack control, 1" leveling binder and 2" surface course. Area 3 (Library and Fire Station #1 Parking Lot Improvements - Sidewalks & Striping): The proposed parking lot improvements at the Library and Fire Station #1 include removing and replacing sidewalk, partial curb and gutter removal and replacement, full -depth pavement patching (5"), and new pavement markings. Area 4 (Kensington Court and Kensington Road Pavement Patching): This area includes approximately 30% Class D patching (8") along Kensington Court for approximately 900 feet and along Kensington Road as determined by the Engineer during construction. The proposed patches will consist of 6" of hot -mix asphalt binder course and 2" of hot -mix asphalt surface course. Location of the pavement patches will be determined in the field by the Engineer. Area 5 (Brook Forest Subdivision Pavement Patching): The proposed pavement patching of select streets In the Brook Forest subdivision involves approximately 10% Class D patching (10") of deteriorated pavement sections along Kimberley Lane, Pembroke Lane, Charieton Place and Shelburne Drive; approximately 4,200 feet. The proposed patching will consist of 8" of hot -mix asphalt binder course and 2" of hot -mix asphalt surface course. Location of the pavement patches will be determined in the field by the Engineer. Area 6 (Butler Government Center Parking Lot): This area includes reconstructing a portion of the Butler Government Center (Village Hall) parking lot at the east entrance and as shown in the attached location map. The proposed improvement will include full depth removal of the existing asphalt pavement (3") and removal of an additional 2" of aggregate base course in order to provide for the installation of a new 5" pavement section. The proposed pavement section will consist of 3" of hot -mix asphalt binder course and 2" of hot -mix asphalt surface course. Area 7 (York Road Guard Rail Extension): This area includes replacing and extending the existing guard rail along the east side of York Road, north of the bridge over 1-88. The work will include extending the existing guard rail with approximately 140 linear feet of Steel Plate Beam Guardrail, Type A, and 1 each Traffic Barrier Terminal, Type 2. The estimated construction budget for the 2012 Miscellaneous Paving Project Is $2,250,000. it is anticipated that all areas will be bid as one project and constructed during the 2012 construction season. SCOPE OF SERVICES A detailed scope of Construction Engineering services is provided below including, but not limited to, the following: Task 1 — pre -Construction: Management of the pre -construction meeting. OCGgmc Page 2 of 5 NAPROPOSALMOMIM201210ak Brook -2012 Paving ProjecFPhase111,040412.doc Task 2 — Construction Observation: CBBEL will provide one full-time resident engineer and one part-time project engineer (as necessary) for the duration of the project. Construction observation will include the following tasks: • Provide resident/business communication, including written communication as required, throughout the duration of the project. • Serve as the Village's liaison with the Contractor working principally through the Contractor's field superintendent. • Be present whenever the Contractor is performing work on the project. • Observe the progress and quality of the executed work and to determine if the work is proceeding in accordance with the Contract Documents. The Engineer will keep the Village informed of the progress of the work, guard the Village against defects and deficiencies in the work, advise the Village of all observed deficiencies of the work, and will disapprove or reject all work failing to conform to the Contract Documents. • Quality control of the construction work In progress and the enforcement of the contract provisions in accordance with (DOT's Construction Manual. • Keep an inspectors daily report book as outlined in the IDOT Construction Manual, which shall contain a daily report and quantity of hours on the job site, weather conditions, list of visiting officials, daily activities, job decisions and observations as well as general and specific observations and job progress. • Maintain a daily record of the contractor's activities throughout construction including sufficient information to permit verification of the nature and cost of changes in plans and authorized extra work. • Measurement and computation of pay items. • Preparation and submission of all partial and final payment estimates, change orders, records, documentation and reports. • Except upon written instructions of the Village, the Resident Engineer or Inspector shad not authorize any deviation from the Contract Documents. • Assist contractors in dealing with any outside agencies. Attend all construction conferences. Arrange a -schedule of progress meetings and other job conferences as required. Maintain and circulate copies of records of the meetings. • Attend meetings at any reasonable time when requested to do so by representatives of the Village. • Review the Contractor's schedule on a weekly basis. Compare actual progress to Contractor's approved schedule. If the project falls behind schedule, work with the Contractor to determine the appropriate course of action to get back on schedule. • Maintain orderly files for correspondence, reports of job conferences, shop drawings and other submissions, reproductions or original contract documents including all addenda, change orders and additional drawings issued subsequent to the award of the contract. • Prepare payment requisitions and change orders for the Village's approval, review applications for payment with the Contractor for compliance with established procedures for their submission and forward them with recommendations to the Village. Ocq= NAPR0P0$AL$MMW204210ek &ook•2012 Patine Proj"WhasAI.040412.doc Page 3 of 5 • Prior to final inspection, submit to the Contractor a list of observed items requiring correction and verify that each correction has been made. • Coordinate and conduct the final inspection with the Village, prepare a final punchlist. • Verify that all the items on the final punchlist have been corrected and make recommendations to the Village concerning acceptance. • Determine if the project has been completed in accordance with the Contract Documents and that the Contractor has fulfilled all of his obligations. Please note that for any of the observation tasks that CBBEL may be performing, the Contractor(s) shall be informed that neither the presence of CBBEL field staff nor the observation and testing (if any) by our firm or subconsultant of our firm shall excuse the Contractor in any way for defects discovered in the work. It should be understood that CBBEL will not be responsible for any job and site safety on this project; job and site safety shall be the sole responsibility of the Contractor(s). CBBEL does not have the right to stop work and will not advise nor supervise the Contractor(s) means and methods of their work. Task 3 — Protect Close Out: • Revision of contract drawings to reflect as built conditions (Microstation format). • All final paperwork will be submitted to the Village • Material Inspection close out will be submitted to the Village in accordance with the Construction Manual and Bureau of Materials standards. Task 4 — Material Testing: CBBEL will provide material inspection services through our sub -consultant Testing Service Corporation (TSC) of Carol Stream, IL. TSC will complete the Quality Assurance (QA) material testing for concrete and asphalt at the site and QA testing at the plants in accordance with (DOT's Construction Manual. It is understood that CBBEL will be responsible for the performance of material inspection services as described above. It is also understood that CBBEL is the sole representative of the Village. An additional 20% contingency has been added in order to provide additional material testing, if necessary. Ocolmo WWROP Ba e 4 of 5 N?PROPOSALSW�MIN@01210ak Brook -2012 Paving Project-PTase111.040d12.doc g DETERMINATION OF FEE CBBEL proposes the following not to exceed fees for each of the tasks described above for each Area: CONSTRUCTION ENGINEERING SERVICES Task 1 — Pre -Construction $ 500 Task 2 — Construction Observation $120,0001 Task 3 — Project Close Out $ 4,000 Task 4 — Material Testing 9,000 Sub Total $133,500 DIRECT COSTS Outside Copies, Blueprints, Messenger, Delivery Services Total $ 1,000 GRAND TOTAL $134,500 We will bill you at the hourly rates specified on the attached Schedule of Charges and establish our contract in accordance with the attached General Terms and Conditions. Please note the direct costs for blueprints, photocopying, mailing, overnight delivery, messenger services and report compilation are included in the not to exceed Fee Determination and will not be charged separately for this project. These General Terms and Conditions are expressly incorporated into and are an integral part of this contract for professional services. Please sign and return one copy of this agreement as an indication of acceptance and notice to proceed. Please feel free to contact us anytime. Christopher B. Burke, PhD, PE, D.WRE, F.ASCE President Encl. Schedule of Charges General Terms and Conditions THIS PROPOSAL, SCHEDULE OF CHARGES AND GENERAL TERMS AND CONDITIONS ACCEPTED FOR THE VILLAGE OF OAK BROOK: BY: TITLE: DATE: Occrmo Page 5 of 5 N:IPROPOSAMMOM0201210ak Brook.2012 Paving ProleCFPhaseIR040412.doC CHRISTOPHER B. BURKE ENGINEERING, LTD. STANDARD CHARGES FOR PROFESSIONAL SERVICES JANUARY, 2012 Personnel Principal Engineer VI Engineer V Engineer IV Engineer III Engineer 1/II Survey V Survey IV Survey III Survey II Survey i Resource Planner V Resource Planner IV Resource Planner III Resource Planner 1/II Engineering Technician V Engineering Technician IV Engineering Technician III Engineering Technician 1/I1 CAD Manager Assistant CAD Manager CAD II CAD GIS Specialist III GIS Specialist 1/11 Lat$dscape Architect j? Environmental Resource Specialist V Environmental Resource Specialist IV Environmental Resource Specialist III Environmental Resource Specialist 1/I1 Environmental Resource Technician Administrative Engineering Intern Survey Intern Information Technician III Information Technician 1/II Direct Costs Outside Copies, Blueprints, Messenger, Delivery Services, Mileage 'Charges include overhead and profit Charges` /Hr 240 210 173 138 125 102 178 132 127 100 78 112 108 100 88 150 132 107 97 138 126 125 98 120 67 138 154 134 114 94 90 88 53 53 97 62 Cost + 12% Please note. In recognition of the economic challenges facing our clients, we have not increased our schedule of charges since January 2009. CHRISTOPHER B. BURKE ENGINEERING, LTD. GENERAL TERMS AND CONDITIONS Relationship Between Engineer and Client: Christopher B. Burke Engineering, Ltd. (Engineer) shall serve as Client's professional engineer consultant in those phases of the Project to which this Agreement applies. This relationship is that of a buyer and seller of professional services and as such the Engineer is an independent contractor in the performance of this Agreement and itis understood thatthe parties have not entered into anyjoint venture or partnership with the other. The Engineer shall not be considered to be the agent of the Client. Nothing contained in this Agreement shall create a contractual relationship with a cause of action in favor of a third party against either the Client or Engineer. Furthermore, causes of action between the parties to this Agreement pertaining to acts of failures to act shall be deemed to have accrued and the applicable statute of limitations shall commence to run not later than the date of substantial completion. 2. Responsibility of the Engineer: Engineer will strive to perform services under this Agreement in accordance with generally accepted and currently recognized engineering practices and principles, and in a manner consistent with that level of care and skill ordinarily exercised by members of the profession currently practicing in the same locality under similar conditions. No other representation, express or implied, and no warranty or guarantee is included or intended in this Agreement, or in any report, opinion, document, or otherwise. Notwithstanding anything to the contrary whichmay be contained in this Agreement or any other material incorporated herein by reference, or in any Agreement between the Client and any other party concerning the Project, the Engineer shall not have control or be in charge of and shall not be responsible for the means, methods, techniques, sequences or procedures of construction, or the safety, safety precautions or programs of the Client, the construction contractor, other contractors or subcontractors performing any of the work or providing any of the services on the Project. Nor shall the Engineer be responsible for the acts or omissions of the Client, or for the failure of the Client, any architect, engineer, consultant, contractor or subcontractor to carry out their respective responsibilities in accordance with the Project documents, this Agreement or any other agreement concerning the Project. Any provision which purports to amend this provision shall be without effect unless it contains a reference that the content of this condition is expressly amended for the purposes described in such amendment and is signed by the Engineer. 3. Changes: Client reserves the right by written change order or amendment to make changes in requirements, amount of work, or engineering time schedule adjustments, and Engineer and Client shall negotiate appropriate adjustments acceptable to both parties to accommodate any changes, if commercially possible. 4. Suspension of Services: Client may, at any time, by written order to Engineer (Suspension of Services Order) require Engineer to stop all, or any part, of the services required by this Agreement. Upon receipt of such an order, Engineer shall immediately comply with its terms and take all reasonable steps to minimize the costs associated with the services affected by such order. Client, however, shall pay all costs incurred by the suspension, including all costs necessary to maintain continuity and forthe resumptions of the services upon expiration of the Suspension of Services Order. Engineer will not be obligated to provide the same personnel employed prior to suspension, when the services are resumed, in the event that the period of suspension is greater than thirty (30) days. 5. Termination: This Agreement may be terminated by either party upon thirty (30) days written notice in the event of substantial failure by the other party to perform in accordance with the terms hereof through no fault of the terminating party. This Agreement may be terminated by Client, urder the same terms, whenever Client shall determine that termination is in its best interests. Cost of termination, including salaries, overhead and fee, incurred by Engineer either before or after the termination date shall be reimbursed by Client. 6. Documents Delivered to Client: Drawings, specifications, reports, and any other Project Documents prepared by Engineer in connection with any or all of the services furnished hereunder shall be delivered to the Client for the use of the Client. Engineer shall have the right to retain originals of all Project Documents and drawings for its files. Furthermore, it is understood and agreed that the Project Documents such as, but not limited to reports, calculations, drawings, and specifications prepared for the Project, whether in hard copy or machine readable form, are instruments of professional service intended for one-time use in the construction of this Project. These Project Documents are and shall remain the property of the Engineer. The Client may retain copies, including copies stored on magnetic tape or disk, for information and reference in connection with the occupancy and use of the Project. When and if record drawings are to be provided bythe Engineer, Client understands that information used in the preparation of record drawings is provided by others and Engineer is not responsible for accuracy, completeness, nor sufficiency of such information. Client also understands that the level of detail illustrated by record drawings will generally be the same as the level of detail illustrated by the design drawing used for project construction. If additional detail is requested by the Client to be included on the record drawings, then the Client understands and agrees that the Engineer will be due additional compensation for additional services. It is also understood and agreed that because of the possibility that information and data delivered in machine readable form may be altered, whether inadvertently or otherwise, the Engineer reserves the right to retain the original tapes/disks and to remove from copies provided to the Client all identification reflecting the involvement of the Engineer in their preparation. The Engineer also reserves the right to retain hard copy originals of all Project Documentation delivered to the Client in machine readable form, which originals shall be referred to and shall govern iri fhe event of any iricoiisi§tericy between the two. The Client understands that the automated conversion of information and data from the system and format used by the Engineer to an alternate system or format cannot be accomplished without the introduction of inexactitudes, anomalies, and errors. In the event Project Documentation provided to the Client in machine readable form is so converted, the Client agrees to assume all risks associated therewith and, to the fullest extent permitted bylaw, to hold harmless and Indemnify the Engineer from and against all claims, liabilities, losses, damages, and costs, including but not limited to attorney's fees, arising therefrom or in connection therewith. The Client recognizes that changes or modifications to the Engineer's instruments of professional service introduced by anyone other than the Engineer may result in adverse consequences which the Engineer can neither predict nor control. Therefore, and in consideration of the Engineer's agreement to deliver its instruments of professional service in machine readable form, the Client agrees, to the fullest extent permitted by law, to hold harmless and indemnify the Engineerfrom and againstall claims, liabilities, losses, damages, and costs, including but not limited to attorney's fees, arising out of or in anyway connected with the modification, misinterpretation, misuse, or reuse by others of the machine readable information and data provided by the Engineer under this Agreement. The foregoing indemnification applies, without limitation, to any use of the Project Documentation on other projects, for additions to this Project, or for completion of this Project by others, excepting only such use as may be authorized, in writing, by the Engineer. 7. Reuse of Documents: All Project Documents including but not limited to reports, opinions of probable costs, drawings and specifications furnished by Engineer pursuant to this Agreement are intended for use on the Project only, They cannot be used by Client or others on extensions of the Project or any other project. Any reuse, without specific written verification or adaptation by Engineer, shall be at Client's sole risk, and Client shall indemnify and hold harmless Engineer from all claims, damages, losses, and expenses including attorney's fees arising out of or resulting therefrom. The Engineer shall have the right to include representations of the design of the Project, including photographs of the exterior and interior, among the Engineer's promotional and professional materials. The Engineer's materials shall not include the Client's confidential and proprietary information if the Client has previously advised the Engineer in writing of the specific information considered by the Client to be confidential and proprietary. 8. St_andardofPractice: The Engineer will strive to conduct services under this agreement in a mariner consistent with that level of care and skill ordinarily exercised by rnernbers of the profession currently practicing in the same locality under similar conditions as of the date of this Agreement. 9. Compliance With Laws: The Engineer will strive to exercise usual and customary professional care in his/her efforts to comply with those laws, codes, ordinance and regulations which are in effect as of the date of this Agreement. With specific respect to prescribed requirements of the Americans with Disabilities Act of 1990 or certified state or local accessibility regulations (ADA), Client understands ADA is a civil rights legislation and that interpretation of ADA is a legal issue and not adesign issue and, accordingly, retention of legal counsel (by Client) for purposes of interpretation is advisable. As such and with respect to ADA, Client agrees to waive any action against Engineer, and to indemnifyand defend Engineer against any claim arising from Engineer's alleged failure to meet ADA requirements prescribed. Further to the law and code compliance, the Client understands that the Engineer will strive to provide designs in accordance with the prevailing Standards of Practice as previously set forth, but that the Engineer does not warrant that any reviewing agency having jurisdiction will not for its own purposes comment, request changes and/or additions to such designs. in the event such design requests are made by a reviewing agency, but which do not exist in the form of a written regulation, ordinance or other similar document as published by the reviewing agency, then such design changes (at substantial variance from the intended design developed by the Engineer), if effected and incorporated into the project documents by the Engineer, shall be considered as Supplementary Task(s) to the Engineer's Scope of Service and compensated for accordingly. 10. Indemnification: Engineer shall indemnify and hold harmless Client up to the amount of this contract fee (for services) from loss or expense, including reasonable attorney's fees for claims for personal injury (including death) or property damage to the extent caused by the sole negligent act, error or omission of Engineer. Client shall indemnify and hold harmless Engineer under this Agreement, from loss or expense, including reasonable attorney's fees, for claims for personal injuries (Including death) or propertydamage arising out of the sole negligent act, error omission of Client. In the event of joint or concurrent negligence of Engineer and Client, each shall bearthat portion of the loss or expense that its share of the joint or concurrent negligence bears to the total negligence (including that of third parties), which caused the personal injury or property damage. Engineer shall not be liable for special, incidental or consequential damages, including, but not limited to loss of profits, revenue, use of capital, claims of customers, cost of purchased or replacement power, or for any other loss of any nature, whether based on contract, tort, negligence, strict liability or otherwise, by reasons of the services rendered under this Agreement. 11. Opinions of Probable_ Cost: Since Engineer has no control over the cost of labor, materials or equipment, oroverthe Contractors) method of determining process, or over competitive bidding or market conditions, his/her opinions of probable Project Construction Cost provided for herein are to be made on the basis of his/her experience and qualifications and represent his/herjudgement as a design professional familiar with the construction industry, but Engineer cannot and does not guarantee that proposal, bids or the Construction Cost will not vary from opinions of probable construction cost prepared by him/her. If prior to the Bidding or Negotiating Phase, Client wishes greater accuracy as to the Construction Cost, the Client shall employ an independent cost estimator Consultant for the purpose of obtaining a second construction cost opinion independent from Engineer. 12, Governing Law & Dispute Resolutions: This Agreement shall be governed by and construed in accordance with Articles previously set forth by (Item 9 of) this Agreement, together with the laws of theState of Illinois. Any claim, dispute or other matter in question arising out of or related to this Agreement, which cannot be mutually resolved by the parties of this Agreement, shall be subject to mediation as a condition precedent to arbitration (if arbitration is agreed upon by the parties of this Agreement) or the institution of legal or equitable proceedings by either party. If such matter relates to or is the subject of a lien arising out of the Engineer's services, the Engineer may proceed in accordance with applicable lawto complywith the lien notice or filing deadlines prior to resolution of the matter by mediation or by arbitration. The Client and Engineer shall endeavor to resolve claims, disputes and other matters in question between them by mediation which, unless the parties mutually agree otherwise, shall be in accordance with the Construction Industry Mediation Rules of the American Arbitration Association currently in effect. Requests for mediation shall be filed in writing with the other party to this Agreement and with the American Arbitration Association. The request may be made concurrently with the filing of a demand for arbitration but, in such event, mediation shall proceed in advance of arbitration or legal or equitable proceedings, which shall be stayed pending mediation for a period of 60 days from the date of filing, unless stayed for a longer period by agreement of the parties or court order. The parties shall share the mediator's fee and any filing fees equally. The mediation shall be held in the place where the Project is located, unless another location is mutually agreed upon. Agreements reached in mediation shall be enforceable as settlement agreements in any court having jurisdiction thereof. 13. Successors and Assigns: The terms of this Agreement shall be binding upon and inure to the benefit of the parties and their respective successors and assigns: provided, however, that neither party shall assign this Agreement in whole or in part without the prior written approval of the other. 14. Waiver of Contract Breach: The waiver of one party of any breach of this Agreement or the failure of one party to enforce at any time, or for any period of time, any of the provisions hereof, shall be limited to the particular instance, shall not operate or be deemed to waive any future breaches of this Agreement and shall not be construed to be a waiver of any provision, except for the particular instance. 15. Entire Understanding of Agreement: This Agreement represents and incorporates the entire understanding of the parties hereto, and each party acknowledges that there are no warranties, representations, covenants or understandings of any kind, matter or description whatsoever, made by either party to the other except as expressly set forth herein. Client and the Engineer hereby agree that any purchase orders, invoices, confirmations, acknowledgments or other similar documents executed or delivered with respect to the subject matter hereof that conflict with the terms of the Agreement shall be null, void and without effect to the extent they conflict with the terms of this Agreement. 16. Amendment: This Agreement shall not be subject to amendment unless another instrument is duly executed by duly authorized representatives of each ofthe parties and entitled "Amendment of Agreement". 17. Severability of Invalid Provisions: If any provision of the Agreement shall be held to contravene or to be invalid under the lawsof any particular state, county orjurisdiction where used, such contravention shall not invalidate the entire Agreement, but it shall be construed as if not containing the particular provisions held to be invalid in the particular state, country or jurisdiction and the rights or obligations of the parties hereto shall be construed and enforced accordingly. 18. Force Maieure: Neither Client nor Engineer shall be liable for any fault or delay caused by any contingency beyond their control including but not limited to acts of God, wars, strikes, walkouts, fires, natural calamities, or demands or requirements of governmental agencies. 19. Subcontracts: Engineer may subcontract portions of the work, but each subcontractor must be approved by Client in writing. 20. Access and Permits: Client shall arrange for Engineer to enter upon public and private property and obtain all necessary approvals and permits required from all governmental authorities having jurisdiction over the Project. Client shall pay costs (including Engineer's employee salaries, overhead and fee) incident to any effort by Engineer toward assisting Client in such access, permitsor approvals, if Engineer perform such services. 21. Designation of Authorized Representative: Each party (to this Agreement) shall designate one or more persons to actwith authority in its behalf in respect to appropriate aspects of the Project. The persons designated shall review and respond promptlyto all communications received from the other party. 22. Notices: Any notice or designation required to be given to either party hereto shall be in writing, and unless receipt of such notice is expressly required by the terms hereof shall be deemed to be effectively served when deposited in the mail with sufficient first class postage affixed, and addressed to the party to whom such notice is directed at such party's place of business or such other address as either party shall hereafter furnish to the other party by written notice as herein provided. 23. Limit of Liability: The Client and the Engineer have discussed the risks, rewards, and benefits of the project and the Engineer's total fee for services. In recognition of the relative risks and benefits of the Project to both the Client and the Engineer, the risks have been allocated such that the Client agrees that to the fullest extent permitted by law, the Engineer's total aggregate liability to the Client for any and allinjuries, claims, costs, losses, expenses, damages of any nature whatsoever or claim expenses arising out of this Agreementfrom any cause or causes, including attorneys fees and costs, and expert witness fees and costs, shall not exceed the total Engineer's fee for professional engineering services rendered on this project as made part of this Agreement. Such causes included but are not limited to the Engineers negligence, errors, omissions, strict liability or breach of contract. It is intended that this limitation apply to any and all liability or cause of action however alleged or arising, unless otherwise prohibited by law. 24. Client's Responsibilities: The Client agrees to provide full information regarding requirements for and about the Project, including a program which shall set forth the Client's objectives, schedule, constraints, criteria, special equipment, systems and site requirements. The Client agrees to furnish and pay for all legal, accounting and insurance counseling services as may be necessary at any time for the Project, including auditing services which the Client may require to verify the Contractor's Application for Payment or to ascertain how or for what purpose the Contractor has used the money paid by or on behalf of the Client. The Client agrees to require the Contractor, to the fullest extent permitted by law, to indemnify, hold harmless, and defend the Engineer, its consultants, and the employees and agents of any of them from and against any and all claims, suits, demands, liabilities, losses, damages, and costs ("Losses"), including but not limited to costs of defense, arising in whole or in part out of the negligence of the Contractor, its subcontractors, the officers, employees, agents, and subcontractors of any of them, or anyone for whose acts any of them may be liable, regardless of whetheror not such Losses are caused in part by a party indemnified hereunder. Specifically excluded from the foregoing are Losses arising out of the preparation or approval of maps, drawings, opinions, reports, surveys, change orders, designs, or specifications, and the giving of or failure to give directions by the Engineer, its consultants, and the agents and employees of any of them, provided such giving or failure to give is the primarycause of Loss. The Client also agrees to require the Contractor to provide to the Engineer the required certificate of insurance. The Client further agrees to require the Contractor to name the Engineer, its agents and consultants as additional insureds on the Contractor's policy or policies of comprehensive or commercial general liability insurance. Such insurance shall include products and completed operations and contractual liability coverages, shall be primary and noncontributing with any insurance maintained by the Engineer or its agents and consultants, and shall provide that the Engineer be given thirty days, unqualified written notice prior to any cancellation thereof. In the event the foregoing requirements, or any of them, are not established by the Client and met by the Contractor, the Client agrees to indemnify and hold harmless the Engineer, its employees, agents, and consultants from and against any and all Losses which would have been indemnified and insured against by the Contractor, but were not. When Contract Documents prepared under the Scope of Services of this contract require insurance(s) to be provided, obtained and/or otherwise maintained by the Contractor, the Client agrees to be wholly responsible for setting forth any and all such insurance requirements. Furthermore, any document provided for Client review by the Engineer under this Contract related to such insurance(s) shall be considered as sample insurance requirements and not the recommendation of the Engineer. Client agrees to have their own risk management department review any and all insurance requirements for adequacy and to determine specific types of insurance(s) required for the project. Client further agrees that decisions concerning types and amounts of insurance are specific to the project and shall be the product of the Client. As such, any and all insurance requirements made part of Contract Documents prepared by the Engineer are not to be considered the Engineer's recommendation, and the Client shall make the final decision regarding insurance requirements. 25. Information Provided by Others: The Engineer shall indicate to the Client the information needed for rendering of the services of this Agreement. The Client shall provide to the Engineer such information as is available to the Client and the Client's consultants and contractors, and the Engineer shall be entitled to rely upon the accuracy and completeness thereof. The Client recognizes that it is impossible for the Engineer to assure the accuracy, completeness and sufficiency of such information, either because it is impossible to verify, or because of errors or omissions which may have occurred in assembling the information the Client is providing. Accordingly, the Client agrees, to the fullest extent permitted by law, to indemnify and hold the Engineer and the Engineer's subconsultants harmless from any claim, liability or cost (including reasonable attorneys' fees and cost of defense) for injury or loss arising or allegedly arising from errors, omissions or inaccuracies in documents or other information provided by the Client to the Engineer. 26. Payment: Client shall be invoiced once each month for work performed during the preceding period. Client agrees to pay each invoice within thirty (30) days of its receipt. The client further agrees to pay interest on all amounts invoiced and not paid or objected to for valid cause within said thirty (30) day period at the rate of eighteen (18) percent per annum (or the maximum interest rate permitted under applicable law, whichever is the lesser) until paid. Client further agrees to pay Engineer's cost of collection of all amounts due and unpaid after sixty (60) days, including court costs and reasonable attorney's fees, as well as costs attributed to suspension of services accordingly and as follows: Collection Costs. In the event legal action is necessary to enforce the payment provisions of this Agreement, the Engineer shall be entitled to collect from the Client anyjudgement or settlement sums due, reasonable attorneys' fees, court costs and expenses incurred by the Engineer in connection therewith and, in addition, the reasonable value of the Engineer's time and expenses spent in connection with such collection action, computed at the Engineer's prevailing fee schedule and expense policies. Suspension of Services. If the Client fails to make payments when due or otherwise is in breach of this Agreement, the Engineer may suspend performance of services upon five (5) calendar days' notice to the Client. The Engineer shall have no liability whatsoever to the Client for any casts or damages as a result of such suspension caused by any breach of this Agreement by the Client. Client will reimburse Engineer for all associated costs as previously set forth in (Item 4 of) this Agreement. 27. When construction observation tasks are part of the service to be performed by the Engineer under this Agreement, the Client will include the following clause in the construction contract documents and Client agrees not to modify or delete it: Kotecki Waiver. Contractor (and any subcontractor into whose subcontract this clause is incorporated) agrees to assume the entire liability for all personal injury claims suffered by its own employees, including without limitation claims under the Illinois Structural Work Act, asserted by persons allegedly injured on the Project; waives any limitation of liability defense based upon the Worker's Compensation Act, court interpretations of said Act or otherwise; and to the fullest extent permitted by law, agrees to indemnify and hold harmless and defend Owner and Engineer and their agents, employees and consultants (the "Indemnitees") from and against all such loss, expense, damage or injury, including reasonable attorneys' fees, that the Indemnitees may sustain as a result of such claims, except to the extent that Illinois law prohibits indemnity for the Indemnitees' own negligence, The Owner and Engineer are designated and recognized as explicit third party beneficiaries of the Kotecki Waiver within the general contract and all subcontracts entered into in furtherance of thegeneral contract. 28. Job Site Safety/Supervision & Construction Observation: The Engineer shall neither have control over or charge of, nor be responsible for, the construction means, methods, techniques, sequences of procedures, or for safety precautions and programs in connection with the Work since they are solely the Contractor's rights and responsibilities. The Client agrees that the Contractor shall supervise and direct the work efficiently with his/her best skill and attention; and that the Contractor shall be solely responsible for the means, methods, techniques, sequences and procedures of construction and safety at the job site. The Client agrees and warrants that this intent shall be carried out in the Client's contractwith the Contractor. The Client further agrees that the Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the work; and that the Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injuryor loss to all employees on the subject site and all other persons who may be affected thereby. The Engineershali have no authorityto stop the work of the Contractor or the work of any subcontractor on the project. When construction observation services are included in the Scope of Services, the Engineer shall visit the site at intervals appropriate to the stage of the Contractor's operation, or as otherwise agreed to by the Client and the Engineer to; 1) become generally familiar with and to keep the Client informed about the progress and quality of the Work; 2) to strive to bring to the Client's attention defects and deficiencies in the Work and; 3) to determine in general If the Work is being performed in a manner indicating that the Work, when fully completed, will bein accordance with the Contract Documents. However, the Engineer shall not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. If the client desires more extensive project observation, the Client shall request that such services be provided by the Engineer as Additional and Supplemental Construction Observation Services in accordance with the terms of this Agreement. The Engineer shall not be responsible for any acts or omissions of the Contractor, subcontractor, any entity performing any portions of the Work, or any agents or employees of any of them. The Engineer does not guarantee the performance of the Contractor and shall not be responsible for the Contractor's failure to perform its Work in accordance with the Contract Documents or any applicable laws, codes, rules or regulations. When municipal review services are included in the Scope of Services, the Engineer (acting on behalf of the municipality), when acting in good faith in the discharge of its duties, shall not thereby render itself liable personally and is, to the maximum extent permitted by law, relieved from all liability for any damage that may accrue to persons or property by reason of any act or omission in the discharge of its duties. Any suit brought against the Engineer which involve the acts or omissions performed by it in the enforcement of any provisions of the Client's rules, regulation and/or ordinance shall be defended by the Client until final termination of the proceedings. The Engineer shall be entitled to all defenses and municipal immunities that are, or would be, available to the Client. 29. Insurance and Indemnification: The Engineer and the Client understand and agree that the Client will contractually require the Contractor to defend and indemnify the Engineer and/or any subconsultants from any claims arising from the Work. The Engineer and the Client further understand and agree that the Client will contractually require the Contractor to procure commercial general liability insurance naming the Engineer as an additional named insured with respect to the work. The Contractor shall provide to the Client certificates of insurance evidencing that the contractually required insurance coverage has been procured. However, the Contractor's failure to provide the Clientwith the requisite certificates of insurance shall not constitute a waiver of this provision bythe Engineer. The Client and Engineer waive all rights against each other and against the Contractor and consultants, agents and employees of each of them for damages to the extent covered by property insurance during construction. The Client and Engineer each shall require similar waivers from the Contractor, consultants, agents and persons or entities awarded separate contracts administered under the Client's own forces. 30. Hazardous Materials/Pollutants: Unless otherwise provided by this Agreement, the Engineer and Engineer's consultants shall have no responsibility for the discovery, presence, handling, removal or disposal of or exposure of persons to hazardous materials/pollutants in any form at the Project site, including but not limited to mold/mildew, asbestos, asbestos products, polychlorinated biphenyl (PCB) or other toxic/hazardous/pollutant type substances. Furthermore, Client understands that the presence of mold/mildew and the like are results of prolonged or repeated exposure to moisture and the lack of corrective action. Client also understands that corrective action is a operation, maintenance and repair activity for which the Engineer is not responsible. June 13, 2005 PAProposalfferms and Conditions\GT&C 2005.061305.doc 10